3 Templates of Construction General Contracting Contracts
Construction project contracting should conclude a written contract in accordance with the law, clarifying the rights and obligations of both parties. How to write a simple contract for engineering construction contracting? The following is a simple contract for construction engineering contracting that I have compiled. Welcome to read it.
Construction general contracting contract template 1
Construction unit (Party A): ___________
Contracting unit (Party B):
p>
In accordance with the "Contract Law of the People's Republic of China" and relevant laws and regulations, Party A and Party B signed this contract based on the principles of equal negotiation, honesty and trustworthiness, and both parties agree to abide by it.
1. Project Overview
1. Project Name: Circulating Water Zero Workshop Renovation Project
2. Project Location: ___________
3 , Project content: The design and transformation content of the construction drawings mainly includes arc screen pool, air flotation pool, fourth-level biological filter, workshop anti-slip floor and drainage ditch transformation, and equipment room transformation.
2. Construction period requirements
The construction period of this project is 40 calendar days. Due to design changes, bad weather or other force majeure factors, the construction period can be postponed accordingly after consensus reached by both parties. If the construction period is delayed by one day without reason, 5‰ of the total project payment will be deducted.
3. Contracting method
This project is contracted by contracting the work, and all project raw materials and construction auxiliary materials are provided by the construction unit.
This project may not be subcontracted.
4. Contract Price
The contract construction cost of this project is 515,000 yuan (five hundred and one thousand and five thousand). If there are changes in the design or an increase or decrease in the project quantity, the actual project quantity will be adjusted with reference to the contractor's quotation.
5. Project quality and acceptance
1. Project quality standard: qualified
2. The construction unit ensures construction according to the design drawings, and the construction unit ensures the quality of raw materials.
3. After the completion of concealed projects and individual projects, the construction unit shall immediately submit an acceptance notice, and the construction unit shall conduct quality acceptance of the project.
6. Main responsibilities of both parties
(1) Party A
1. Provide detailed construction drawings in a timely manner.
2. Supply raw materials in time and ensure quality.
3. Send representatives to the construction site to supervise and inspect the materials, quality and progress of the project, and coordinate various matters that occur on site.
4. Pay the project payment as stipulated in the contract and bear all consequences caused by default in project payment.
(2) Party B
1. Erection of water and electric lines within the construction area.
2. Carry out construction in strict accordance with the design drawings to ensure project quality and progress.
3. Actively cooperate with Party A to coordinate and resolve various matters that occur on site.
4. Carry out civilized construction, place tools and materials neatly, and ensure the rational use of materials. Any waste of raw materials caused shall be compensated according to the price.
5. Construction shall be carried out in strict accordance with the production safety operating procedures. If a work-related injury occurs due to illegal operation, Party A will be solely responsible for it and Party A will not bear any responsibility.
6. In accordance with the construction requirements of the construction project, provide construction logs, issue official national tax invoices, and cooperate with Party A in the acceptance work. Specific matters shall be negotiated by both parties based on actual circumstances.
7. Project payment
After completing all contract contents, 95% of the contract price will be paid. The other 5% will be used as a quality deposit and will be paid off without interest one year from the date of completion.
8. Liability for breach of contract
If any dispute arises between the two parties, it should be resolved through negotiation. If negotiation fails, a lawsuit can be filed with the Laizhou Municipal People's Court.
9. Supplementary Provisions
This contract is in duplicate and will take effect after being signed and sealed by representatives of both parties.
Party A: ___________ Party B:
Legal representative: Legal representative:
Address: Sanshan Island Street Address, Laizhou City:
Contact number: Contact number:
Construction general contracting contract template 2
Building unit: (hereinafter referred to as Party A)
Contracting unit: (hereinafter referred to as Party A) Party B)
1. Project Overview
1. Project Location:
2. Project Name:
3. Construction Area: Press Actual area calculation. The total building area is not less than
2. All items of the project: contracting work, contracting materials, depreciation and new construction, water and electricity installation: sewage pipes, removal of slag, garbage, indoor 888, bathroom, kitchen, fire room wall tiles Floor tiles, switches, sockets, faucets, etc.
3. Project cost: Yuan per square meter. The total price is 10,000.
4. Construction date: month, except for weather reasons (such as rainy days). If any construction is overdue, Party B shall compensate Party A for losses and be fined RMB 100 for one day overdue. Based on this calculation, it will be deducted from the total project payment.
The construction period starts from year month day to day.
5. Payment method: Payment on schedule, that is, % of the total price will be paid after the demolition of the old house is completed and the foundation is poured, % will be paid after the second floor roof slab is placed, and % will be paid after the main body is completed. After passing the inspection, the total amount left will be the warranty deposit, and the rest will be settled, and Party A will return the warranty deposit in one go.
6. Construction requirements: Party B must follow the design drawings, pay attention to technical quality, and pay attention to safety, and must not cut corners, commit fraud, or deceive Party A. Otherwise, Party A has the right to stop the construction and be held accountable.
1. Party B shall issue building construction drawings, water and electricity drawings, nearby construction requirements and construction process flow sheets, etc., and construction shall be carried out according to the drawings after confirmation by Party A.
2. The floor slab must be 10-12 centimeters thick. After the floor tiles and wall tiles are laid, there should be no loose or uneven joints, uneven texture, reflections, bumps, or improper joints. There should be no uneven ground and water accumulation after the ceramic tiles are laid.
3. After the wall is scraped, there should be no unevenness, scraping marks, scratches or unevenness. Scraping is required 3 times.
4. The foundation and cast-in-situ reinforced concrete require "Pingtang" brand No. 42.5 cement. Other brands of 32.5 cement can be used for bricklaying, copper core wires are used for indoor concealed wires, and the wire cross-section for main wires and kitchen cooking utensils is not less than 4cm2. The cross-section of the socket cord in each room shall not be less than 2.5cm2. All wires must be wrapped in conduit.
5. The first floor of the house is 3.2 meters high, and the second and third floors are 3.0 meters high. The roof, balcony, kitchen, and bathroom must be tested for waterproofing and must not leak or accumulate water. You are responsible for the corresponding measures. compensation.
6. If Party B causes damage to the neighbor’s house during the construction project, Party B will be responsible for everything.
7. If Party B deliberately conceals some projects that must be implemented during the building decoration design process, and then requires additional costs during the construction process, Party A has the right not to increase any costs.
8. The ground should be waterproof and moisture-proof.
9. Each room must have no less than 4 7-hole sockets (excluding air conditioners, TVs, and network cables), 2 lamps, and reserve 2 light wires. The first and fourth floors of the house must be The four-and-a-half-story turret is also cast-in-situ, and the rest is made of prefabricated panels.
10. Each construction material must be inspected and accepted by Party A before construction can begin.
11. During the demolition and construction process of the project, the quality, safety and sanitation of the site must be ensured. The above process must comply with the requirements of the urban management and street communities. The fence around the project must be two stories high. If the requirements are not met, no start. The construction process must not disturb residents, and construction will stop after 10 p.m.
7. Building materials: Steel, cement, sand, wires, water pipes, sewage pipes, door and window frames, prefabricated panels, switches, sockets, faucets and other materials must be nationally certified products.
1. Grade I steel should be produced by Xiangtan Iron and Steel Co., Ltd.
2. Grade II steel should be Shuangling brand rebar produced by Lianyang Iron and Steel Co., Ltd.
3. Doors (roller shutters, security doors, solid wood doors).
4. The steel material of columns and beams is 14φ.
5. Party B is responsible for laying up all floor tiles and floor tiles on the first floor. The cost of 100 square meters for the second to fourth floors is 100 yuan per square meter (including laying floor tiles and smoothing cement on the stairs.)
6. 42.5 grade cement produced by Cement Pingtang.
7. Electrical appliance materials: West Lake Jinbei copper wire produced in Hengyang.
Socket switch: produced by a national genuine manufacturer.
8. Windows: Xiangrui famous brand plastic steel windows are used.
9. The sewage pipes for water supply and drainage are produced by genuine national manufacturers (diameter 200mm).
10. If the foundation foot excavation depth exceeds 1 meter, it will be resolved through negotiation between the two parties.
8. Scope of safety responsibilities: Party B shall be responsible for all man-made and non-man-made safety accidents, large and small, from the date of the start of construction until the new house is completed and handed over and Party A accepts it. During this period, including the demolition of the old house and the construction of the new house, Party B shall , and Party A will not bear any responsibility for violations of the law and fines, so Party A requires Party B to put safety production first and quality first, and implement civilized construction from beginning to end.
9. Security: During the construction period, Party B will be responsible for security work during the day and night until the completion is approved by Party A.
10. Party A’s responsibilities: Make preparations before the start of construction, and coordinate and handle the relationship with neighbors and surrounding units. Supervise construction, supervise progress, inspect materials and project quality, and deal with problems in a timely manner when problems are discovered. If Party A wants to change the construction plan, it should promptly discuss it with Party B. If the value of the plan exceeds RMB, Party A should compensate Party B appropriately. No compensation will be given if the amount does not exceed RMB.
11. Supplementary Provisions
1. This contract is made in two copies, with Party A and Party B each holding one copy.
2. This contract will take effect from the date it is signed and sealed by both parties, and will terminate when the project is completed and accepted and the project payment is settled.
3. After the signing of this contract, if Party A and Party B need to propose modifications, they will make additions after negotiation between both parties.
Party A (signature, seal): Party B (signature, seal):
Year, month, day, year, month, day
Construction General Contracting Contract Sample 3
Project name: ______
Project number: ______
Contractor: ______
Contractor: ______
Signing time: ______
Signing place: ______
According to the "Contract Law of the People's Republic of China" and the "Construction and Installation Project Contract Regulations" and relevant regulations, in order to clarify The rights, obligations and economic responsibilities of both parties during the construction process shall be determined after both parties negotiate and agree to sign this contract.
Article 1 Project
1. Project Name: ______
2. Project Location: ______
3. Project Approval Unit______
Approval number ________ (referring to the number of the authority with the authority to approve the project)
Project supervisory unit: ______
4. Contracting Scope and content: (See the project list for details); Project construction area ______ (square meters); Others: ______
5. Project cost: ______ (ten thousand yuan), including civil construction: ______ (ten thousand yuan) ), installation: ______ (10,000 yuan)
Article 2 Construction Preparation
1. Contractor:
1. To be done before ____month____ days It is good to build the "three links" outside the red line and be responsible for the maintenance of the access roads outside the red line.
2. Before ____month____, be responsible for connecting the general construction water source, power supply, and transformer (including water meter, distribution board) at the construction site, which should meet the needs of construction water and electricity consumption. . Prepare information on site leveling and removal of obstacles within the red line.
3. Submit the building permit within ____ days after signing this contract.
4. Within ____ days after the contract is signed (subject to the last drawing received), ____ copies of complete building and installation construction drawings, construction technical information (including geology and benchmark point coordinates) Control points)____ copies.
5. Organize both contracting parties, the design unit and relevant departments to participate in the construction drawing disclosure review, and prepare the disclosure review minutes signed by the three parties, and distribute them to the relevant units within ____ days, and provide them within ____ days ____ copies of joint review minutes and revised construction drawings.
2. Contractor:
1. Responsible for the laying, management, use and maintenance of temporary roads, temporary facilities, and water and electricity pipelines in the construction area;
2. Organize construction management personnel, materials, and construction machinery to enter the site;
3. Prepare construction organization design or construction plan, construction budget, overall construction progress plan, and site entry plan for materials and equipment, finished products, semi-finished products, etc. ( Including monthly plans), water and electricity consumption plans, and delivery of packages.
Article 3 Project Duration
1. According to the national construction period quota and usage needs, it is agreed that the total project duration is ____ days (calendar days), starting from ____ year___ Construction will start on ____ month ____ and will be completed and accepted on ____ month ____ of ____ (the start and completion date of each unit's project is attached, see Appendix 1).
2. ____ days before the start of construction, the contractor shall issue a notice of commencement of work to the contractor.
3. In the following circumstances, the construction period will be postponed accordingly after obtaining the visa from the on-site representative of the contractor:
1. According to the construction preparation regulations, the construction site, water, power supply and roads cannot be provided. It can be connected, but the obstacles cannot be removed, which affects the construction on site;
2. Where the materials, equipment, finished products or semi-finished products supplied by the contractor cannot meet the construction requirements or due to defects found during inspection, Repair, replacement, replacement and replacement will affect the progress;
3. Major design changes that are not within the scope of the lump sum coefficient, the engineering geological data provided are inaccurate, resulting in changes in the design plan or reasons why construction cannot be carried out. And affect the progress;
4. During construction, if there is a power outage or water outage for more than 8 hours, or a continuous intermittent water or power outage for more than 3 days (each time for more than 4 hours in a row), it will affect the normal construction; < /p>
5. The supervision visa is not issued in time due to reasons other than the contractor’s, which affects the construction of the next process;
6. Failure to allocate advance payment, project progress payment or price difference for purchased materials as stipulated in the contract. Affecting the construction;
7. Delaying the construction period due to force majeure factors.
Article 4 Project Quality
1. The quality of this project has been studied by both parties to meet the following requirements: ____
2. The contractor must strictly follow the construction drawings and documentation. Carry out construction in accordance with the construction engineering codes, regulations and standards issued by the state, and accept the supervision of representatives from the contract issuing party.
3. The contractor must comply with the following regulations during the construction process:
1. The main raw materials, equipment, components, and semi-finished products provided by the contractor must be of qualified quality in accordance with relevant regulations Certificate, or can only be used in the project after passing the inspection;
2. The main raw materials, equipment, components and semi-finished products provided by the contractor must also have quality certificates before they can be used in the project. Any change or substitution of materials must be approved by the original design unit and issued with a formal written notice and a visa from the contractor's representative before it can be used in the project;
3. Concealed projects must be inspected, signed and signed by the contractor's representative Only then can the next process be carried out;
4. The contractor shall assess the project quality by item, division and unit project according to the quality assessment standards, and promptly submit the unit project quality assessment results to The contractor and the quality supervision station. When the unit's project structure is completed, it should conduct an intermediate acceptance of the structure together with the contractor and the quality supervision station;
5. If a quality accident occurs during construction, the contractor should promptly report to the representative of the contractor and the local construction project quality supervisor stand. The results of general quality accidents should be sent to the contractor and the quality supervision station for record; the treatment plan for major quality accidents should be jointly studied by the design unit, the quality supervision station, the contractor and other units, and implemented after being signed by the design and construction unit. ;
6. After the project is completed, the contractor will perform warranty on the project in accordance with regulations, and the warranty period will be calculated from the date of completion acceptance.
Article 5 Supply, acceptance and price difference processing of construction materials and equipment
1. The following materials and equipment shall be supplied by the contractor in kind or in specifications (see Appendix 2 for details);
2. Materials and equipment other than those supplied by the contracting party shall be purchased by the contractor;
3. Materials and equipment supplied by the contracting party and purchased by the contractor must be accompanied by product qualification certificates The certificate can only be used for the project. If either party believes that the materials provided by the other party need to be re-inspected, re-inspection shall be allowed. If it meets the quality requirements after re-inspection, it can be used in the project, and the re-inspection fee will be borne by the party requesting re-inspection; if it does not meet the quality requirements, it should be handled in accordance with relevant regulations, and the re-inspection fee will be borne by the party providing materials and equipment.
4. How to deal with the price difference of materials and equipment for this project: ____
Article 6 Payment and settlement of project price
Payment and settlement of project price, It should be implemented in accordance with the "Capital Construction Project Price Settlement Methods" formulated by the People's Construction Bank of China.
1. Within ____ days after the signing of this contract, the contractor shall pay no less than ____% of the total contract price (or investment amount for the year) for materials preparation, totaling RMB____ million yuan; temporary facilities The fee is calculated as ____% of the total cost of the civil engineering contract and is calculated as RMB ____ million yuan. The installation project is calculated as ____% of the labor cost and is calculated as RMB ____ million yuan. The price difference of materials and equipment is ____ million yuan, divided into ____ Payment, time and amount of each payment____.
2. After receiving the monthly project progress report from the contractor, the contract issuing party must pay the progress payment according to the verified project progress within ____ days. When the project progress payment reaches ____% of the total contract price, The reserve funds will gradually be deducted according to the prescribed proportion.
3. When the payment of the project price reaches 95% of the total contract price, payment will no longer be made according to the progress. After completion of the handover acceptance, the warranty period will be expired with principal and interest (financial appropriation does not include interest) and will be paid in one lump sum to Contractor.
4. If the contracting party defaults on the progress payment or final payment of the project, it shall pay the contractor ____ ten thousandth of the default amount as liquidated damages for each day of arrears.
5. If the progress of the project is indeed affected by the contract-issuing party's arrears of project payment and price difference for purchased materials, resulting in the contractor's stoppage or delay in work, the contract-issuing party shall bear the responsibility.
6. The cost settlement method of this contract: ____
7. The contractor shall submit the completion settlement documents to the contracting party and the handling bank within ____ days after the completion acceptance of a single project. The contractor shall complete the review within ____ days after receiving the settlement documents. If no written objection is raised within the expiration date, the contractor may request the handling bank to allocate funds after approval.
Article 7 Construction and Design Changes
1. The design drawings, descriptions and relevant technical information delivered by the contractor shall be used as the effective basis for construction. The contractor shall organize a design briefing before the start of construction. The joint review minutes will be prepared with the three parties as a supplementary basis for the construction, and neither the contracting party nor the contracting party shall modify them without authorization.
2. If an error or serious unreasonable design is found during construction, the contractor shall promptly notify the contract-offering party in writing, and the contract-offering party shall promptly study and determine modification opinions or change the design documents together with the design and other relevant units. , the contractor carries out construction according to the modified or changed design documents. If additional costs occur (including rework losses, work stoppages, delayed work, relocation of personnel and machinery and equipment, and actual losses from the backlog of materials and components), the contractor will be responsible for it and adjust the contract price.
3. Under the premise of ensuring the quality of the project and not lowering the design standards, the contractor puts forward reasonable suggestions for modifying the design and modifying the process, which will be implemented after being approved by the contractor, the design unit or the relevant technical department. The value of savings is distributed according to national regulations.
4. If the contractor needs to change the design, the original design unit must issue a formal modification notice and revised drawings before the contractor can implement it. Major modifications or cost increases must be negotiated separately, and the contract will not be implemented until the investment implementation certificate is obtained and the technical data and design drawings are complete.
Article 8 Project Acceptance
1. The acceptance of completed projects shall be based on the "Interim Provisions on Completion Acceptance of Capital Construction Projects", "Project Construction and Acceptance Specifications", "Architecture "Installation Project Quality Inspection and Assessment Standards" and the completion acceptance regulations and construction drawings and instructions and construction technical documents formulated by the relevant departments of the State Council.
2. Underground engineering and structural engineering during project construction must have records such as concealed acceptance certificates, pressure tests, water tests, and anti-seepage records. After the completed quality of the project is inspected by the local quality supervision department, the contracting party must go through the acceptance visa procedures in a timely manner.
3. The project can only be used after the project is completed and accepted.
During the specified warranty period, all quality accidents and quality defects caused by construction shall be covered by the contractor free of charge. The warranty conditions, scope and period shall be implemented in accordance with the "Construction Project Warranty Measures (Trial)" issued by the Ministry of Urban and Rural Development and Environmental Protection (84) Chengjian Zi Notice No. 79.
Article 9 Liability for breach of contract
Responsibilities of the contractor:
1. If the quality of the project does not meet the provisions of the contract, it will be responsible for free repair or rework. If delivery is overdue due to repair or rework, overdue liquidated damages will be paid.
2. If the project cannot be delivered for use within the construction period specified in the contract, overdue fines shall be paid in accordance with Article 9 of the contract regarding rewards and penalties for advancing or delaying the construction period.
Responsibilities of the contractor:
1. If it fails to perform its responsibilities in accordance with the provisions of the contract, in addition to the postponement of the completion date, it shall also compensate the contractor for any resulting losses. actual loss.
2. If the project is stopped midway, delayed or reworked due to design changes or design errors, measures should be taken to make up for or reduce losses. At the same time, the contractor shall be compensated for actual losses caused by work stoppages, delays, rework, reshipping, relocation of personnel and machinery, and backlog of materials and components.
3. If the project is not received and the contract-issuing party uses it in advance or uses it without authorization, the contract-issuing party shall be responsible for any quality or other problems arising therefrom.
4. If the contractor fails to conduct acceptance after the acceptance notice is delivered to ____, overdue liquidated damages shall be paid in accordance with regulations.
5. Failure to allocate project funds as stipulated in the contract, and the contractor's compensation shall be reimbursed with a deferred payment amount of 30,000% per day in accordance with the bank's provisions on overdue payment methods.
Article 10 Dispute Resolution
Any dispute arising from the execution of this contract shall be resolved through negotiation between the parties. If negotiation fails, both parties agree to arbitrate by the _____ Arbitration Commission (if the parties do not agree on an arbitration institution in this contract and do not reach a written arbitration agreement afterwards, they may sue in the People's Court).
Article 11 Supplementary Provisions
1. This contract is made in ____ copies, and there are ____ copies of the contract attachments. Party A and Party B shall each keep one original copy, and the remaining copies shall be submitted by the contract issuing party to the handling bank, the local industrial and commercial administration agency, and the construction department for recordation. For contracts that require forensic (notarization) certification according to regulations, the contracts must be submitted to the industrial and commercial and notary authorities where the building is located for certification (notarization).
2. This contract will take effect when signed by representatives of both parties and stamped with the official seals or contract-specific seals of both parties. If a forensic (notarial) certificate is required, it will take effect from the date of the completion of the forensic (notarial) certificate; Project The project will be terminated after the completion acceptance meets the requirements and the project payment is settled.
3. After this contract is signed, if the contracting party and the contracting party need to propose modifications, they can sign a supplementary agreement as a supplementary contract to this contract after both parties reach consensus through negotiation.
Contract issuing party (seal):
Representative (signature):
Address:
Telephone:
Year, month and day
Contractor (seal)
Representative (signature and seal):
Address:
Telephone :
Year, month and day
3 related articles on construction general contracting contract templates:
★ 3 latest construction general contracting contract templates in 2020
★ 3 pieces of construction general contracting contract templates in 2020
★ 3 latest standards of construction general contracting contract templates
★ Construction general contracting contract templates
★ 3 templates of construction project general contracting contracts
★ 3 templates of project construction general contracting contracts
★ 3 templates of project contracting contracts
★ Project contracting contracts 3 general version templates
★ 3 construction project contract templates
★ 3 general contract management contract templates