Project Construction Agreement
In today’s society, agreements are used in more and more places. Once you sign an agreement, you have legal support. So how to write the relevant agreement? Below are 4 project construction agreements that I have collected and compiled. You are welcome to learn from them and refer to them. I hope they will be helpful to you. Project Construction Agreement Part 1
Party A: (hereinafter referred to as Party A)
Party B: (hereinafter referred to as Party B)
In accordance with the "People's Republic of China "Contract Law of the People's Republic of China", "Construction Project Quality Management Regulations" and other relevant laws and administrative regulations, following the principles of equality, voluntariness, fairness and good faith, both parties reach consensus on house maintenance matters and enter into this contract.
1. Project Overview
1. Project Name:
2. Project Location:
3. Project Scope:
4. The contract period: the start date is year month day, and the completion date is year month day. This construction period includes legal holidays, cross construction, and waiting time for cooperative construction. , due to weather or other factors affecting the construction, Party B can appropriately extend the construction period after Party A’s confirmation and consent.
2. Engineering service form
Contracting work, materials, construction period, and quality.
3. Settlement method
Party A and B and the supervisor will counter-sign the technical contact form on the parts to be repaired and the amount of the work. The amount of the work will be signed by Party A, B and the supervisor. The content of the signed and confirmed technical contact form will be used as the basis to determine the total project cost.
Party A and Party B shall attach the settlement statement signed and sealed by both parties and the engineering quantity technical contact sheet signed by Party A and Party B and the supervisor *** as attachments to the contract.
IV. The total project price
is tentatively determined to be RMB 10,000 (the final settlement value shall be subject to the settlement value confirmed by Party A and Party B).
5. Project Quality Supervision, Inspection and Acceptance
During construction, Party B must strictly comply with national and industry standards and enterprise specifications as well as the provisions of this contract, and accept inspections from Party A at any time. , and provide convenient conditions for inspection and inspection. Party B shall rectify the problems raised by Party A in a timely manner. After the maintenance project is completed, both parties A and B and the owner of the house being repaired shall jointly inspect and accept the project. If the acceptance is passed The "Construction Record Sheet" signed and confirmed by the three parties shall prevail. During the completion acceptance, Party B shall be responsible for continuing the repairs according to Party A's requirements for any project quality problems that have not yet been repaired and confirmed by Party A or the owner
and shall bear overdue liability.
6. Project payment
After the project is completed and accepted, 97% of the total project payment will be paid, and the remaining 3% will be used as a quality deposit. After the warranty period expires, if there are no quality problems, the full amount will be paid. Party B.
VII. Warranty
1. After the completion of Party B’s maintenance project, Party B shall assume warranty responsibility for the entire project. The warranty period is one year. After the project is completed and accepted and delivered to Party A, Calculated from date.
2. The project warranty fund is % of the project price. Within ten days after the expiration of the warranty period, Party A will return the remaining part of the warranty fund without interest.
3. During the warranty period, if there is a quality problem in the maintenance project, Party B shall ensure that it sends personnel to inspect and repair within 2 hours after receiving the notice from Party A, and shall repair it within a reasonable period determined by Party A. After completion, if Party B fails to send someone to repair within the time limit or problems still occur after the second repair, Party A has the right to entrust others to repair the problem, and the costs and losses incurred by Party A as a result shall be borne by Party B.
4. Party B must strictly abide by the construction process requirements during construction. If mold and leakage problems occur again in the repaired project, Party B shall complete the repairs within two days after receiving Party A’s notification and bear the responsibility. All impacts and financial compensation consequences caused by the recurrence of mold and leakage problems. Such as household decoration, compensation for damage to items, etc.
5. During the warranty period, Party B shall conduct regular inspections of the construction project, keep records of return visits, and resolve hidden quality problems in a timely manner. Party B now reserves the written mailing address and phone number of the person in charge of the warranty in order to notify Party B for repairs.
8. Liability for breach of contract
1. If Party B delays the start of construction, fails to complete construction, or fails to perform other obligations within the prescribed time limit, it shall bear the tentative total project cost to Party A for each day overdue. If any of the liquidated damages is overdue for seven days or there are more than three delays (including three) in total, Party A has the right to terminate the contract, and Party B shall bear all losses caused by Party A (including Party A's resulting losses to the third party). compensation and liquidated damages paid by three parties).
2. If Party B suspends work for more than two days (including two days) without Party A’s permission, Party A has the right to terminate the contract, and Party B shall unconditionally withdraw from the site within two days. Both parties will settle the settlement after Party B withdraws.
3. Party B violates any other obligation in this contract and Party A notifies it to make corrections within a time limit. If it still fails to make corrections after the expiration of the period, Party A has the right to terminate this contract, and Party B shall bear the consequences of this. All losses to Party A.
4. If Party B intentionally or negligently causes project quality problems caused by materials and construction techniques that do not comply with technical specifications and environmental protection requirements, or are inconsistent with the contract, regardless of whether the project has been accepted and delivered, and Whether the warranty period has expired, Party A or the owner shall have the right to claim compensation against Party B within two years from the date when Party A or the owner becomes aware of it.
5. Party B shall not transfer the rights and obligations under this contract to others without the written consent of Party A. Otherwise, Party A has the right to terminate the contract.
6. Party A has the right to refuse to pay any payment before the quality problems of the parts repaired by Party B are resolved.
7. If this contract is terminated due to Party B’s reasons, Party B shall bear 10% of the provisional price of the contract as liquidated damages. If the liquidated damages are insufficient to compensate for the losses suffered by Party A (including Party A shall pay compensation and liquidated damages to the third party as a result, and Party B shall also compensate Party A for the losses suffered.
9. Safe construction
Party B shall adopt strict construction safety measures in accordance with relevant regulations and bear the responsibility for accidents caused by its own inadequate safety measures and the resulting costs and consequences. Party B’s construction personnel Party B is responsible for personal safety. Party B shall purchase personal accident insurance for construction personnel and all insurances related to project construction. Party B will be held responsible for any safety or other liability accidents that occur during the construction process.
10. Construction Responsibilities
1. Party A provides Party B with water, electricity and other conveniences during the construction, and is responsible for coordinating with the residents and relevant subordinate departments. Party B shall construct according to the construction technology requirements.
2. Party B must protect the square brick paths, flowers, plants and trees in the community during construction and not damage them. Maintenance at residents' homes must strictly abide by the system of property regulations. If there are complaints from residents or Party B damages items, Party A has the right to deduct it from the project payment payable to Party B.
3. Party B appoints a representative at the construction site for this project to organize the construction in accordance with the requirements of this contract, ensure quality, quantity, and complete the content stipulated in this contract on schedule. He is also responsible for communicating and contacting Party A. Any commitments, guarantees, letters, signatures, confirmations, etc. made by the person in charge to Party A regarding this project will be regarded as the actions of Party B, and Party B will be responsible for them.
4. Party B shall carry out construction in strict accordance with the construction practices and quality standards confirmed by Party A, and make various quality inspection records. Strictly implement construction specifications, safe operating procedures, fire safety regulations, and environmental protection regulations to ensure that the project meets the contract and Party A's requirements.
5. Party B is responsible for protecting all on-site facilities and finished and semi-finished products and bearing the costs before the project is completed and accepted and delivered for use.
6. During maintenance, Party B must collect garbage at Party A’s designated location every day, keep the construction site clean, and remove it within the time required by Party A. Clean and dispose of it before completion. Otherwise, Party A has the right to entrust others to clean up, and the costs incurred shall be deducted from the project payment payable to Party B.
7. Accept quality inspection, inspection and supervision from Party A’s representatives and their designated personnel at any time during construction, provide convenient conditions for inspection, inspection and supervision, and comply with the requirements of Party A’s representatives and their designated personnel. Rework and modifications, bear the costs of rework and modifications due to one's own reasons.
8. All approval procedures required for maintenance construction (referring to items that need to be submitted for approval according to relevant laws and regulations) shall be handled and borne by Party B, and all responsibilities shall be borne by Party B.
9. The maintenance project agreed in this contract must be completed by Party B itself. Without the consent of Party A, Party B shall not subcontract, subcontract or hand over the project to any other third party for completion. Otherwise, Party A has the right to terminate this contract.
10. Party B should pay attention to maintaining good communication with the maintenance owner during the maintenance process to avoid disputes. If Party B has a dispute with the maintenance owner due to Party B's reasons and causes Party A to suffer losses, Party B shall bear the responsibility. Party A has the right to deduct the project payment payable to Party B, and Party A has the right to recover the shortfall from Party B.
11. During the maintenance and construction process, Party B shall pay attention to protecting the property and items of Party A and the owner, and shall not damage the buildings and related facilities and equipment in the community. During the maintenance project, Party B shall compensate Party A or a third party for personal or property damage caused by Party B. Party A has the right to deduct the project payment payable to Party B, and Party A, the owner or the relevant rights holder has the right to recover the shortfall from Party B.
11. Others
1. If this project involves confirmation of the project price, the relevant confirmation must be confirmed by Party A’s representative, Party A’s budget department and stamped with Party A’s official seal In order to be valid, Party A will not recognize the signature of anyone else (except the legal representative) or the lack of any of the aforementioned confirmations, or the official seal of Party A (such as a visa stamp, etc.).
2. If the confirmation of the project quantity is involved, it must be counter-signed by Party A’s representative and the engineering department manager and stamped with Party A’s special visa stamp before it is valid. Both are indispensable.
3. The settlement statement determined by Party A and Party B and the engineering quantity technical contact sheet signed by Party A and Party B and the supervisor *** are included as attachments to this contract and have the same legal effect as this contract.
4. This contract is made in three copies, with Party A holding four copies and Party B holding two copies. This contract shall take effect from the date of signature and seal by Party A and Party B.
5. If any unfinished matters or disputes arise during the execution of the contract, both parties should resolve them through friendly negotiation. If negotiation fails, the matter shall be settled by the People's Court where the maintenance project is located.
Party A: Party B:
(Seal) (Seal)
Legal representative: Legal representative:
( Signature) (Signature)
Person in charge: Person in charge:
(Signature) (Signature) Project Construction Agreement Part 2
Party A: Hangzhou Project Department of Section A of the Phase II of the Fourth Construction Jin** City Garden Lot D
Party B:
After friendly negotiation between Party A and Party B, Party A has transferred 29#, 31#, Projects 32#, 34#, 36#, 38#, and 39#
are contracted to Party B for construction. In order to ensure the smooth progress of the project, the agreement is hereby signed
as follows:
1. Party B is responsible for all sporadic work such as the unevenness of nails in the indoor ceiling, the removal of concrete, etc. During the water maintenance test in the kitchen and bathroom, if there is leakage or seepage that affects the quality of the coating project, Party B shall be obliged to take the initiative to repair it. During the construction of the air-conditioning hole, Party B will be responsible for repairing the contaminated wall surface, and handling the details of the elastic lines at the inner corners of the ceiling if the size deviation exceeds the specification requirements.
Party A provides Party B with an outdoor distribution box, and on-site construction operating conditions such as vertical transportation derricks will not be added based on the existing configuration.
2. Use black cement to repair the uneven seams in the ceiling panels. If black cement is used to scrape the ceiling over a large area, a fine of 100 yuan will be imposed for each set.
3. Party B must construct according to the drawings and establish a safety network, identify full-time security management personnel, and Party A conducts relevant safety education.
4. Safety belts must be worn when working at heights, and safety helmets must be worn when entering the work area. Illegal construction or barbaric construction is not allowed.
5. All management work during the construction will be the responsibility of Party B’s construction team leader and supervised by Party A. If a safety accident occurs, Party B will be fully responsible.
6. Party B must ensure quality and time to complete the construction period on the premise of ensuring safety. If it is delayed for one day, it will be fined 1,000 yuan, and so on.
7. This agreement is valid from the date of signing until the project is accepted.
8. If anyone is found to be stealing, fighting, or gambling, he will be fined 3,000 yuan once he is found. If he is found the second time, he will be cleared out and this agreement will be invalid. If the situation is serious, he will be handed over to the public security agency for handling.
9. This agreement is made in duplicate, with Party A and Party B each holding one copy.
10. The construction period will be until December 20, 20xx.
11. Payment method: 800 yuan/person for workers’ living expenses will be paid monthly, and 80% of the total project price will be paid when the workers leave the site. 90% of the total project price shall be paid within three months after completion acceptance, and the balance shall be paid after two years (if the repair work is not timely and in place, Party A will arrange repair personnel, and the cost will be deducted from Party B's warranty deposit).
Party B shall submit worker attendance cards and salary cards on the 5th of every month (must be signed by the employee himself). Otherwise, Party B shall be responsible for all consequences after the Municipal Construction Management Office investigates and handles the matter.
Note: During the construction process and after the completion of the project, garbage should be cleaned up in a timely and civilized manner. No throwing or other barbaric construction is allowed
Party A: Hangsi Jianjin** City Garden Lot D Phase 2 A Bid Section Project Department
Party B:
Year, month and day project construction agreement Part 3
Employer: ________
Contractor: ________
In order to further clarify the responsibilities, rights and obligations of Party A and Party B, On the basis of the "Construction Contract of "Shuanglongyuan Commercial and Residential Building Project in Puding County, Anshun City", in accordance with the "Contract Law of the People's Republic of China" and the "Construction Law of the People's Republic of China" and other relevant provisions , and based on the specific conditions of this project, Party A and Party B sign a supplementary agreement to the construction contract of this project with complete voluntariness and understanding of the terms of this supplementary agreement.
1. Project Overview
1. Project Name: ________
2. Project Address: ________
3. Construction Area: ________
4. Structure type: The bottom floor is a frame structure, and the 6+1 floors above ground are a brick-concrete structure.
5. Design unit: ________
6. Supervision unit: ________
2. Project content and contract scope
1. External The wall tiles were replaced with exterior wall paint
2. The sliding door in the living room was cancelled
3. This project has seven floors and the structure needs to be sloped
4. Stairs The cement mortar surface should be clear and polished
5. The 40 × 40 dark gray grid on the exterior wall is cancelled
6. The door with window (MC-2324) between the kitchen and the balcony is cancelled, and the balcony Change to a closed kitchen, agreement "Sample Supplementary Agreement for Project Construction".
7. The rest shall be constructed according to the original drawings
3. Contract duration (the dates listed in this agreement are all calendar days)
1. Opening, Completion date
1.1 Start date: ____year____month____; Completion date: ____year____month____day; The total construction period is ____ days (including statutory holidays) The date stated in the "Construction Project Completion Report" shall prevail.
IV. Payment method
This project is a one-time lump sum based on the construction area, ____ yuan/square meter; during the construction process, if the amount of work is increased as required by Party A, Calculated based on the price negotiated by both parties; this project is the second floor of the main body of advance payment. After the installation of the prefabricated panels on the second floor, Party A will pay 30% of the total contract price to Party B. After the installation of the main five-layer prefabricated panels is completed, Party A will pay 30% of the total contract price. 15% will be paid to Party B. When the main seven floors are completed, Party A will pay Party B 20% of the total contract price. When the interior and exterior decoration is completed, Party A will pay Party B 20% of the total contract price. The rest will be paid one month after the acceptance of the project. 12% will be paid to Party B within the period, and 3% will be retained as guarantee and warranty money, which will be paid in one lump sum after the guarantee and warranty period expires.
5. Effectiveness and termination of the contract, and dispute settlement
1. Except for the normal quality warranty, this contract will be terminated after Party A and Party B have fulfilled all obligations stipulated in this contract.
2. This supplemental agreement is made in three originals (including two originals). Party A and Party B each hold one original and two copies.
3. This supplemental agreement is a non-substantive supplement to the "Construction Contract of Shuanglongyuan Commercial and Residential Building in Puding County, Anshun City". If there is any inconsistency between the two, this supplemental agreement shall prevail.
4. If any dispute arises during the performance of this agreement, it shall be resolved by both parties through negotiation. If the dispute cannot be resolved through negotiation, it shall be submitted to the Chengdu Arbitration Commission.
5. This supplemental agreement shall take effect within 5 days from the date of signature by both parties.
Party A: (seal) Party B: (seal)
Legal representative: Legal representative:
Telephone: Telephone:
Fax: Fax:
Account opening bank: Account opening bank:
Bank account number Bank account number:
Contract signing representative: Contract signing representative: < /p>
Year Month Day Year Month Day Project Construction Agreement Part 4
Employer (Party A): __________________
Contractor (Party B): __________________
Both parties follow the principles of equality, voluntariness, fairness and good faith, reach consensus on this construction project, and enter into this agreement.
1. Project Overview
Project Name: ____________________________
Project Location: ____________________________
Project Content: ____________________________
2. Project Contracting Scope
Contracting Scope: _______________ area shall prevail
3. Agreed Construction Period
Construction Start Date: ______year______month_ No. _____
Completion date of the blank house: ______ month ______ year (if it rains one day during the process, it will be postponed by one day)
Completion date: _____ _Year______month______
The total number of calendar days of the agreed construction period: ______ days
4. Construction period delay: The construction period is delayed due to the following reasons, which has been confirmed by Party A. The construction period shall be postponed accordingly
1. Design changes and increase in project volume;
2. Water, power, and gas outages caused by reasons other than Party B within one week, resulting in a total shutdown of more than ______ hours; < /p>
3. Force majeure natural conditions;
5. Completion of the project: Party B must complete the project in accordance with the completion date stipulated in the agreement. If Party B is unable to complete the construction on the completion date specified in the agreement due to reasons of Party B, Party B shall bear liability for breach of contract.
6. Project quality standards: __________ County Quality Inspection Bureau shall prevail. (Excluding material quality)
7. Agreed price
Amount: Construction area RMB______yuan per square meter × Total square meters of construction area
Project Advance payment: ￥______ ten thousand yuan
Payment on completion date: ______% of the remaining total amount
Project payment settlement: Check that there is no construction within ______ months after the completion date of the project If there is a quality problem, the amount owed will be settled.
8. Documents constituting the agreement
1. This agreement
2. Standards, specifications and related technologies Documents
3. Drawings
Written agreements or documents regarding project negotiations and changes between the two parties shall be deemed to be an integral part of this agreement.
9. Party B promises to Party A to carry out construction and completion in accordance with the agreement and assume the responsibility for project quality warranty within the quality warranty period.
10. Party B must submit a written application to Party A 10 days in advance for the building materials required during the construction process. Party A must provide all the construction materials in a timely manner without delaying work to ensure smooth flow during the construction period. If Party B causes unnecessary waste during the construction process, Party B will compensate according to the market price.
11. Party A has the right to supervise Party B’s project. Party B must construct the internal structure of the pig house in accordance with Party A's requirements. Party A shall not arbitrarily mobilize Party B's construction personnel during Party B's construction process.
12. There are two original copies of this agreement, which are equally valid, and one copy shall be kept by the developer and the contractor respectively.
13. The agreement comes into effect
Time of conclusion of the agreement: _________day of _________month
Place of conclusion of the agreement:_________________________________________
< p> This agreement will take effect after the parties agree on _______________________________.Employer: (Signature)_______________
Telephone: _______________________
Residence: __________________
Contractor: (Signature)_______________
p>
Phone:_________________________
Residence:_________________________