Model curtain wall construction contract
Curtain wall construction contract template 1
Employer (hereinafter referred to as Party A):
The Employer (hereinafter referred to as Party B):
Through equal consultation, Party A and Party B, based on the principle of mutual cooperation, close cooperation and division of responsibilities, have reached the following terms and conditions on the glass curtain wall project of buildings B and C of urban garden apartment for * * * to abide by.
Article 1: Project scope, quantity, unit price and total price.
1. 1 Project scope:
The facade glass curtain wall project of "Buildings B and C of City Garden Apartment" includes the design, supply, processing, installation and completion acceptance data of light gray glass concealed frame curtain wall and transparent glass concealed frame curtain wall in the tower. Among them, MC42, MC39, MC4 1, MQC63, MQC63a, MQC64, MQC53, MQC54, MQC72 and MQC65 are light gray tempered glass curtain walls, and the rest are tempered transparent white glass curtain walls.
1.2 project unit price:
Please refer to the attached quotation for details. )
1.3 Total quantities and total price:
(See the project quotation summary attached to the quotation for details)
1.4 The unit price of this total price remains unchanged at the time of settlement, and the area is settled according to the actual completed area. If there are design changes, engineering negotiations, material changes, etc. The price shall be determined by both parties through supplementary agreement after negotiation.
1.5 This quotation includes the inspection fees for three properties of the glass curtain wall.
Article 2: Engineering Materials
2. 1 glass: the curtain wall glass is made of 6mm thick light gray transparent tempered glass and 6mm thick transparent tempered white glass produced by Dongguan Yintong Glass Co., Ltd., and confirmed according to the glass samples provided by Party B. ..
2.2 aluminum alloy profiles:
6063-T5 aluminum alloy profile produced by Foshan Jingu Aluminum Co., Ltd. is selected. The surface of the aluminum profile is silvery white oxidized, and the thickness of the oxide film meets the requirements of AA 15. It is confirmed according to the samples provided by Party B. ..
2.3 silicone structural adhesive and sealant:
Choose MF8 1 1 silicone structural adhesive and MF889 silicone weatherproof sealant produced by Zhengzhou Zhongyuan rubber factory, and confirm them according to the samples provided by party b. ..
2.4 Curtain wall hole fittings: domestic high-quality seven-character handle.
2.5 Steel components: domestic high-quality Q235b steel profiles.
Article 3: Payment Method
3. 1 Within seven days after the aluminum alloy profiles and steel parts enter the site, Party A shall pay Party B 30% of the total contract price as the progress payment for the first phase of the project;
3.2 Party A shall pay Party B 20% of the total contract price within seven days after the installation of aluminum alloy profiles and steel parts is basically completed;
3.3 Within seven days after the glass installation is basically completed, Party A shall pay Party B 20% of the total contract price;
3.4 After the curtain wall installation is completed, Party A shall pay Party B a progress payment of 80% of the total contract amount;
3.4 Within 30 days after the acceptance, Party A shall pay 97% of the total settlement price to Party B, and the remaining 3%.
3.5 If Party A fails to pay the money according to the terms of the agreement, Party B will send a written notice to Party A within five days of the agreed time. If Party A fails to pay the project payment on time within seven days after receiving the notice, Party B has the right to stop the construction, and Party A will bear all the economic losses and liabilities for breach of contract caused thereby.
Article 4: Responsibilities of both parties
4. 1 Party A's responsibilities:
4. 1. 1 Provide a complete set of architectural construction drawings and structural construction drawings of this project and related design change materials;
4. 1.2 handle the construction permit;
4. 1.3 Before Party B enters the site, clear the obstacles in the construction site that affect Party B's construction;
4. 1.4 Organize the coordination meeting between relevant units and Party B;
4. 1.5 Organize relevant personnel to jointly review Party B's design drawings and sign them;
4. 1.6 Organize and cooperate with quality inspection and relevant departments to supervise and inspect the project quality, sign and recognize the quality acceptance of sub-projects in time, and handle design changes and other necessary project visa management; If concealed works or intermediate works need to be accepted in the project, if Party A fails to be present for acceptance within 48 hours after receiving the notice, it will be deemed as qualified. The quality meets the specified requirements. After 48 hours of acceptance, if the representative of Party A fails to sign, it will be deemed as approval, and Party B can continue the construction.
4. 1.7 Organize and coordinate the construction cooperation between Party B and the civil construction unit;
4. 1.8 After Party B submits a written report on the completion of the project, it will organize relevant departments to accept the glass curtain wall;
Note: If Party A fails to complete the above work according to the content and time agreed in the terms and conditions, resulting in the delay of the construction period, the construction period will be postponed accordingly.
4.2 Party B's responsibilities:
4.2. 1 The curtain wall can only be designed after it is approved by the design unit with curtain wall design qualification and audited by Party A, so as to ensure that the design meets the requirements of relevant national codes, be responsible for the design quality, bear all consequences caused by the design quality problems, and submit the curtain wall design drawings and calculations to Party A. ..
4.2.2 Carry out the construction in strict accordance with the approved design drawings, obey the supervision and management of Party A's on-site representative and project supervisor, correct the problems found in time, be responsible for the project quality, and bear all consequences caused by the project quality problems;
4.2.3 Prepare the construction organization design and time limit for a project schedule, and submit it to Party A for approval;
4.2.4 Be responsible for the storage of all incoming materials and the protection of finished products before acceptance. If any damage occurs during the protection period, the responsible party shall be responsible for repairing the damage caused by Party B at its own expense, otherwise Party A shall bear the additional contract price for Party B's repair;
4.2.5 Strictly abide by the relevant management regulations of the construction site and the civil construction unit to ensure the construction safety and civilized construction;
4.2.6 Make original records of construction, and arrange two sets of all relevant data of the project as completion data to Party A before completion acceptance.
4.2.7 Provide complete completion acceptance data to ensure acceptance. If the project fails to pass the acceptance on time due to Party B's information or other reasons, the losses caused thereby shall be borne by Party B..
Article 5: Construction Period
5. 1 Commencement date: Party A shall notify Party B in writing seven days in advance.
5.2 Total construction period: 40 days for Building B and 50 days for Building C, calculated from the date of signing the contract, meeting the requirements for scaffold leaving the site.
5.3 Extension of construction period: the completion date is delayed due to the following reasons, and the construction period is postponed accordingly;
5.3. 1 Changes in construction procedures and contents caused by design changes and engineering quantity changes;
5.3.2 Within one week, the cumulative stoppage of water supply and power failure not caused by Party B exceeds eight hours;
5.3.3 Explosion, fire, flood, rainstorm, rainstorm and earthquake, etc. Caused by war, turmoil, falling flying objects or reasons not attributable to Party A and Party B;
5.3.4 Party A fails to pay the project payment as stipulated in the contract;
5.3.5 Other work stoppage not caused by Party B;
5.4 Party B shall submit a written report on the contents of the delay and the resulting economic expenses within 7 days after the above-mentioned situation occurs, and the representative of Party A shall give a confirmation reply within 2 days after receiving the report, otherwise it shall be deemed as agreement.
Article 6: Project Quality
6. 1 project quality grade: ensure the project quality reaches the "qualified standard" stipulated by the state, and strive for excellent projects.
6.2 The project acceptance shall be conducted according to the parameters specified by Party A and the current domestic codes and standards.
6.3 After the completion of the project, Party B shall provide Party A with a quality guarantee to ensure that the construction of the glass curtain wall conforms to the design calculation.
Article 7: Design changes
7. 1 If Party A changes the design, it shall notify Party B seven days before the engineering processing or construction. Where Party B has processed or constructed, Party B shall stop immediately after receiving the notice.
7.2 Party A shall be responsible for the losses caused to Party B due to the untimely change notice.
Article 8: Completion, Settlement and Warranty
8. 1 After the project meets the completion acceptance conditions, Party A shall submit an acceptance application to the competent construction department within ten days after receiving Party B's completion report, and organize relevant departments to conduct acceptance; Failing to apply for acceptance within ten days after receiving Party B's completion acceptance report, it is deemed that the completion acceptance report has been approved and the project is completed, and settlement procedures can be handled; If the project is not accepted, it shall be deemed as accepted.
8.2 After the project is completed and accepted, Party B shall submit the settlement book to Party A, and Party A shall complete the audit or put forward audit opinions within ten days after receiving the statement. If the settlement is not handled within ten days after receiving the settlement report without justifiable reasons, it shall be deemed to have accepted the settlement report of Party B, and the interest of the project shall be paid according to the highest loan interest of the same period from the tenth day.
8.3 The warranty period shall be calculated from the date of completion acceptance, lasting for two years, and shall be implemented according to the warranty clauses stipulated by the state.
Article 9: Stop or postpone the project construction.
9. 1 If the construction of the project is stopped or postponed due to force majeure or reasons other than Party A and Party B, and the contract cannot be continued, both parties shall sign a stop or delay agreement.
9.2 After the project is suspended, Party B shall properly protect the completed project and the purchased materials, equipment and appliances and hand them over to Party A, and evacuate its own mechanical equipment and personnel from the site according to Party A's requirements. Party A shall provide necessary conditions for Party B's evacuation as agreed in the contract, pay corresponding economic expenses, pay the completed project price and compensate Party B for related losses.
Article 10: Other
10. 1 All letters, telegrams and related technical materials signed by Party A and Party B are annexes and constituent documents of this contract.
10.2 Any dispute arising from the performance of this contract shall be settled by both parties through friendly negotiation; If negotiation fails, both parties may apply to the relevant competent department for mediation; If mediation fails, you can bring a lawsuit to the court.
10.3 this contract shall come into effect immediately after it is signed and stamped by the dual legal representative or the authorized representative of the legal person. After it takes effect, it shall not unilaterally give up without justifiable reasons, and the giving-up party shall compensate the other party for all economic losses.
10.4 This contract shall be subject to the project acceptance and settlement, and Party A shall pay the completion payment. In addition to the relevant warranty terms, other terms are terminated, and the relevant warranty terms are terminated after the warranty period expires.
10.5 the original of this contract is in duplicate, with each party holding one copy and six copies. All have the same legal effect.
Party A: Party B:
Legal representative:
(or entrusted agent): (or entrusted agent)
Year month day:
Model curtain wall construction contract II
Party A:
Party B:
Based on the principle of friendly consultation between the two parties, combined with the actual situation of the project, and in order to ensure the interests of all parties, the following agreement is reached through consultation:
First, the project content:
Second, the project site selection:
Three. Construction period: 30 days, and the normal working day of Party B's workers is 30 days.
1. The total term of this contract is from _ _ to _ _ years.
2. In case of the following circumstances, the construction period shall be postponed accordingly.
(1) Major design changes within the design scope
(2) Force majeure natural disasters (such as typhoons, earthquakes, weather that cannot be constructed, etc.) affect the project progress;
(3) Party A cannot pay the project payment as agreed in the contract.
(4) The weather that cannot be constructed
Party B shall report the delayed contents to Party A within two days after the above situation occurs. After receiving the report, the representative of Party A shall confirm and reply within two days. If Party A fails to reply within the time limit, Party B may consider that the request has been confirmed.
Fourth, the project price, the glass curtain wall is calculated at RMB per square meter, with an area of about square meters and a cost of about RMB (? ), the project area is calculated according to the actual exposed area, and the increased area of the project is counted separately. In this project, Party B does not include any taxes, invoices, construction application, inspection fees, drawing approval fees and construction legs.
Verb (abbreviation of verb) payment terms
1. After both parties sign the contract, Party A shall pay Party B 30% of the total project price, namely RMB Yuan only (? )
2. When Party B installs the aluminum alloy keel frame, Party A shall pay Party B 35% of the total project price within two days, that is, RMB only (? )。
3. After the glass curtain wall project is installed, Party A shall pay Party B 32% of the total project price within two days, namely RMB (? )。
4. Within one week after the acceptance of the glass curtain wall project in this contract, Party A shall pay Party B the project payment in this contract.
Six, aluminum subentry engineering materials are as follows:
1. The brand is Guangdong Lotus, 120 aluminum series.
2. The glass is 6+ 12A+6 hollow Fortran coated tempered glass.
Seven, project acceptance
1. After the project is completed, Party B shall submit a written application for completion acceptance to Party A. Party A shall arrange the project acceptance within 10 days and notify Party B to participate in the acceptance. Party B shall apply for the acceptance report by itself.
10 days later, if the acceptance is not arranged due to Party A's reasons, it will be deemed that the project meets the requirements of the design and construction scheme, operates normally and is qualified.
2. The project has not been accepted. If Party A needs to start construction, it can only be used after consultation with Party B.. If construction is started without Party B's consent, it shall be deemed as qualified.
3. If the whole project is accepted, the completion acceptance date is the completion date.
4. When the project acceptance results are controversial, please ask a third-party professional engineering supervision company for acceptance, and the supervision company will
Eight, acceptance criteria
1. This project is accepted according to the professional design scheme, Party A's drawings and industry standards;
2. Party A or a professional third party shall participate in the acceptance to reach the curtain wall qualification standard.
Nine. Rights and obligations of both parties
A) rights and obligations of party a
1. Designate the project representative, and all signatures of the project representative shall be regarded as Party A's behavior.
2. Be responsible for the supervision of this project and actively coordinate the construction coordination. Party A is responsible for the relationship between this project and the property and urban management.
3. Be responsible for the review and confirmation of drawings and schemes, the supervision and inspection of project progress, project quality, concealed works, supporting projects and contract execution, and the visa for design drawings change, intermediate acceptance of projects and other necessary visas.
4. Be responsible for the completion acceptance, and organize the acceptance within 10 days after receiving all the completion data submitted by Party B. ..
5. Pay the price stipulated in this contract to Party B according to the contract.
B) rights and obligations of party b
1. Provide the legal person power of attorney of Construction Engineering Co., Ltd.
2. The construction shall be carried out in strict accordance with the design drawings, and the quality and technical indicators shall meet the requirements of various standards and specifications of the project.
3. Organize a construction team with technical level, and make it clear that the person in charge of site technology and construction, main management personnel and technical personnel shall not change at will.
4. Responsible for organizing safe construction, ensuring construction safety and ensuring that no materials or objects fall.
5. Be responsible for handling, solving and handling all accidents and problems related to construction.
6. Party B shall carry out curtain wall construction according to the construction drawings approved by Party A, and Party A shall be responsible for all disputes.
X. Safety responsibility
During the construction period, all the responsibilities for safety accidents caused by Party B's factors shall be borne by Party B, and others shall be determined according to national labor laws and regulations.
XI。 Alteration and termination of the contract
1. After this contract comes into effect, both parties shall not change or terminate this contract except for force majeure (war, severe flood, typhoon and earthquake and force majeure accidents agreed by both parties).
2. During the performance of the contract, in case of force majeure, both parties shall take effective measures to minimize the loss and prevent the loss from expanding. If it is really necessary to change or terminate the contract, the party requesting the change shall promptly notify the other party in writing, and the other party shall, after receiving the notice.
Give a reply within 3 days. If no reply is made within the time limit, it shall be deemed as consent.
Twelve. Dispute resolution method
1. Any dispute arising from the signing, performance, dissolution and termination of this contract or related to this contract shall be settled by both parties through friendly negotiation. If negotiation fails, both parties agree to bring a lawsuit to the people's court where the contract is signed.
2. If the contract project needs testing, Party A must conduct testing before construction; If it is necessary to test Party B's non-cooperation after construction, Party A shall bear the cost of the required materials.
Thirteen. other terms
During the performance of this contract, both parties can coordinate and determine the matters not covered in this contract according to the actual situation.
Fourteen Text and effect of contract
This contract is made in duplicate, one for each party, and shall come into effect after being signed and sealed by the representatives of both parties.
Party A:
party B
Year month day:
Model curtain wall construction contract 3
Party A:
Party B:
Through friendly negotiation between Party A and Party B, Party A decided that Party B should undertake the manufacture and installation of the glass curtain wall and Dabaipo project of Huali Tiandi Haoyuan. In order to clarify the responsibilities of both parties, based on the principle of mutual cooperation, close cooperation and division of responsibilities, according to the Economic Contract Law of the People's Republic of China and relevant regulations, both parties agree to reach the following contract terms for this project, which both parties shall abide by.
I. Contents of the contract:
1, project contracting contents: production and installation of 257m2 glass curtain wall and 350m2 large white glass, etc. , and is responsible for the curtain wall up and down closed processing, fire partition, cleaning and final acceptance and delivery.
2. Party B shall contract the production, processing and installation of the above contents and ensure the quality.
Second, the total project price and quantity:
1. Party B shall undertake the production and installation of this project.
In which: the unit price of 257m2 glass curtain wall is: 65 yuan/m2; Unit price of 350m2 Dabaibo is: 50 yuan/m2; The total contract price is RMB 34,205.
2. The engineering quantity of this contract shall be subject to theoretical calculation for the time being, and the actual engineering quantity recognized by both parties shall prevail when the project is settled, and it shall be adjusted according to the fixed unit price of the contract.
Three, engineering production, installation and quality requirements:
1. All construction drawings of this project shall be designed by Party B according to the requirements of Party A and the design institute, and shall not be manufactured, processed and installed until they are reviewed and signed by the professional head of the design institute and approved by Party A. ..
2. Installation quality: the visual inspection shall be firm in assembly, with dense inlays, even in gluing, complete in accessories, neat and beautiful, and the surface verticality and flatness inspection shall meet the requirements of the national industry standard Technical Specification for Curtain Wall Engineering (JJ102-96).
Fourth, the time limit for a project:
2. Party B shall work closely with the interior decoration to ensure that all the work of this project is completed simultaneously with the whole project.
3. The tentative construction period is: 30 days to complete.
Five, project acceptance quality assurance:
1, the project acceptance shall be carried out according to the current national industry standard (JGJ 102-96).
2. After the completion of the project, Party B shall conduct a comprehensive self-inspection, and put forward written inspection requirements after it is confirmed to be correct. After receiving the notice from Party B, Party A shall organize relevant departments to conduct joint acceptance as soon as possible.
3. Party B guarantees to pass the acceptance of relevant departments. If the acceptance is unqualified, Party A refuses to pay the balance; If it affects the completion of the whole project, Party B shall compensate Party A for its losses.
Terms of payment for intransitive verbs:
1. The project payment shall be paid in RMB according to the payment method stipulated in the contract.
2. Before the completion of the project construction, Party A shall pay the living expenses according to Party B's head (20 yuan/day, once a week).
3. After the project construction is completed, 80% of the total project amount will be paid, and the rest will be paid in one lump sum after the project completion acceptance.
Seven. Responsibility of both parties
Party A's responsibilities:
1. Party A shall provide copies of project design and construction;
3. Pay the money in time according to the contract;
4, coordinate the meeting, timely solve and deal with related problems in the construction process;
5. Party A has the right to require Party B's construction quality problems to be rectified. If the requirements of Party A and relevant standards cannot be met after rectification, Party A has the right to terminate the contract;
6. The sufficient space for Party B to stay and store processed products and equipment is about 200 square meters.
7. Urge all units to protect Party B's products. If intentional damage is found, the responsibility shall be borne by the damaged party, and Party A shall cooperate. ..
8. If the design changes, Party B shall be informed one week in advance, otherwise Party A shall be responsible for scrapping the finished products and semi-finished products;
9. Party A shall be responsible for the subsection acceptance, handover and signature procedures of relevant jobs and processes.
Party B's responsibilities:
1. Ensure the quality of processing and installation, and strictly abide by the technical requirements and relevant specifications and standards specified in Article 3 of this contract;
2. Timely report to Party A the civil construction errors that exceed the specifications and affect the installation of this project;
3. Party B shall be responsible for the shutdown and rework caused by Party B's own reasons during the construction;
4, responsible for the finished product protection before acceptance.
5. Strictly abide by the site construction management system, ensure safe and civilized construction, and carry out the construction in strict accordance with the relevant site safety regulations and systems. In case of safety and quality accidents or property losses of third party personnel, Party B shall be responsible.
6. Party B must organize the construction according to the construction plan approved by Party A. If the planned construction cannot be carried out due to the responsibility of the constructor, Party A has the right to give Party B certain punishment.
7. Party B's site construction management personnel must obey the correct instructions of Party A's site management personnel. Party B must replace uncooperative and incompetent personnel according to Party A's requirements, and the replacement personnel must be on duty within three days.
Eight. others
1. All letters, telegrams and related materials approved by Party A during the performance of this contract are annexes to this contract and have legal effect.
2. This contract has legal effect after being signed. If both parties have any unresolved disputes, they can bring a lawsuit to the local government according to the law.
3. If there are any matters not covered in the performance of this contract, both parties shall solve them separately.
This contract is made in quadruplicate, with Party A and Party B holding two copies respectively. This contract shall come into effect after being signed and sealed by both parties.
Party A: Party B:
Handler: Handler:
Tel: Tel:
Date: Date:
Relevant clauses of curtain wall construction contract model:
★ Model glass curtain wall construction contract
★ Template of Glass Curtain Wall Construction Contract (2)
★ Sample of subcontract construction contract for glass curtain wall
★ Curtain wall contract template
★ Model glass curtain wall installation contract
★ Demonstration curtain wall installation labor service contract
★ Exterior wall coating construction contract sample
★ External wall project contract
★ Model Contract for Exterior Wall Coatings
★ There are 3 model essays on the external wall contract at the construction site.